Skip to main content
Paterson Roofing Contractors
CallCall (973) 555-0100

Terms of Service

Last updated: April 2026

Acceptance of Terms

By accessing and using the Paterson Roofing Contractors website at https://patersonroofingcontractors.com, you agree to be bound by these Terms of Service. If you do not agree with any part of these terms, please do not use our website. Your continued use of the site constitutes acceptance of any modifications to these terms.

Services Description

Paterson Roofing Contractors provides roofing services to residential and commercial property owners throughout Passaic County, New Jersey. Our services include but are not limited to roof repair, roof replacement, roof inspections, storm damage repair, flat roof services, gutter installation, emergency roofing, and commercial roofing. Service availability may vary by location and project scope.

Estimates and Pricing

We provide free, no-obligation estimates for all roofing projects. Estimates are based on our assessment of the work required at the time of inspection and are valid for 30 days unless otherwise stated. Final pricing may differ from initial estimates if additional work is discovered during the project, unforeseen structural issues are identified, material costs change significantly, or the customer requests changes to the original scope of work. Any changes to the agreed-upon price will be communicated and approved in writing before additional work begins.

Warranties and Guarantees

Paterson Roofing Contractors stands behind the quality of our work. Specific warranty terms are provided in writing with each project contract and may include workmanship warranties covering installation and labor, manufacturer warranties on roofing materials (terms vary by product), and extended warranties available through our manufacturer certifications (GAF, CertainTeed). Warranty coverage is subject to the terms and conditions outlined in your individual project contract.

Customer Responsibilities

When engaging Paterson Roofing Contractors for roofing services, you agree to provide accurate information about your property and roofing needs, ensure reasonable access to the work area for our crew and equipment, obtain any necessary permits or homeowner association approvals (we can assist with permit applications), maintain a safe environment around the work area during the project, and make timely payments as outlined in the project contract.

Limitation of Liability

Paterson Roofing Contractors shall not be liable for delays or inability to perform services due to circumstances beyond our reasonable control, including severe weather events, material supply shortages, labor disputes, government restrictions, or acts of nature. Our total liability for any claim arising from our services shall not exceed the total amount paid for the specific service in question.

Intellectual Property

All content on this website, including text, images, logos, graphics, and design elements, is the property of Paterson Roofing Contractors and is protected by copyright and intellectual property laws. You may not reproduce, distribute, modify, or create derivative works from any content on this website without our prior written consent.

Website Use

You agree to use this website only for lawful purposes and in a way that does not infringe the rights of, restrict, or inhibit anyone else's use and enjoyment of the website. Prohibited behavior includes harassing or causing distress to any other user, transmitting obscene or offensive content, disrupting the normal flow of communication on the website, and attempting to gain unauthorized access to any part of the website.

Governing Law

These Terms of Service shall be governed by and construed in accordance with the laws of the State of New Jersey, without regard to its conflict of law provisions. Any legal disputes arising from these terms or your use of our services shall be resolved in the courts of Passaic County, New Jersey.

Dispute Resolution

In the event of a dispute, Paterson Roofing Contractors encourages customers to first contact us directly to resolve the matter. We are committed to fair and prompt resolution of any concerns. If a dispute cannot be resolved through direct communication, both parties agree to attempt mediation before pursuing formal legal action.

Insurance and Licensing

Paterson Roofing Contractors maintains all required licenses and insurance for roofing work in New Jersey, including a New Jersey Home Improvement Contractor (HIC) license, general liability insurance, and workers' compensation insurance. Proof of insurance and licensing is available upon request.

Changes to Terms

Paterson Roofing Contractors reserves the right to modify these Terms of Service at any time. Changes become effective immediately upon posting to this page. We encourage you to review these terms periodically. Your continued use of the website after changes are posted constitutes acceptance of the modified terms.

Contact Information

For questions about these Terms of Service, contact Paterson Roofing Contractors: